Terms and Conditions

These Terms and Conditions govern your use of my website and services as a freelance web designer and developer. By accessing my website or engaging my services, you agree to be bound by these terms.

Please read these terms carefully before using my website or services. If you do not agree with any part of these terms, you should not use my website or engage my services.

Acceptance of Terms

By accessing and using this website or engaging my services, you acknowledge that you have read, understood, and agree to be bound by these Terms and Conditions. These terms apply to all visitors, users, and clients who access or use my services.

I reserve the right to modify these terms at any time. Any changes will be effective immediately upon posting on this website. Your continued use of the website or services after any modifications constitutes acceptance of the updated terms.

Services Description

I provide freelance web design and development services including but not limited to:

• Custom website design and development;
• Responsive web design for mobile and desktop devices;
• Website maintenance and updates;
• E-commerce solutions;
• Search engine optimization (SEO) services;
• Web consultation and strategy services.

Specific services, deliverables, timelines, and costs will be detailed in individual project agreements or contracts.

Client Obligations

As a client, you agree to:

• Provide accurate and complete information necessary for project completion;
• Supply content, images, and materials in a timely manner;
• Respond to requests for feedback and approvals within agreed timeframes;
• Make payments according to the agreed payment schedule;
• Ensure you have the right to use any content you provide;
• Communicate professionally and respectfully.

Delays in providing required materials or feedback may result in project timeline adjustments and potential additional costs.

Payment Terms

Payment terms will be specified in individual project agreements. Generally, the following applies:

Payment Schedule

Projects typically require a deposit before work begins, with the balance due upon completion or according to agreed milestones. Specific payment schedules will be outlined in your project agreement.

Late Payments

Late payments may result in project suspension and potential late fees. Work will not resume until outstanding balances are settled.

Refunds

Refunds are subject to the terms of individual project agreements. Generally, deposits are non-refundable once work has commenced.

Intellectual Property

Intellectual property rights vary depending on the nature of the work and will be specified in project agreements:

Client Content

You retain ownership of all content, images, and materials you provide. You grant me a license to use these materials for the duration of the project.

Final Deliverables

Upon full payment, you will receive ownership rights to the final deliverables as specified in the project agreement. I retain the right to display completed work in my portfolio unless otherwise agreed.

Development Tools and Frameworks

I may use third-party tools, frameworks, and libraries in project development. These remain subject to their respective licenses.

Project Timeline and Delivery

Project timelines are estimates based on the information available at project commencement. Actual delivery dates may vary due to:

• Scope changes or additional requirements;
• Delays in receiving client materials or feedback;
• Technical complexities or unforeseen challenges;
• Third-party dependencies or integrations.

I will communicate any potential delays promptly and work to minimize their impact on your project.

Revisions and Changes

Project agreements will specify the number of revisions included in the project scope. Additional revisions or significant scope changes may incur additional costs and timeline adjustments.

Change requests should be submitted in writing and will be subject to approval before implementation. I will provide estimates for any additional work before proceeding.

Limitation of Liability

My liability is limited to the total amount paid for the specific project. I am not liable for:

• Indirect, consequential, or incidental damages;
• Loss of profits, revenue, or business opportunities;
• Third-party claims or damages;
• Issues arising from client-provided content or materials;
• Technical issues beyond my reasonable control.

I strive to deliver high-quality work but cannot guarantee specific business outcomes or results from the services provided.

Termination

Either party may terminate a project agreement with written notice. Termination terms will be specified in individual project agreements.

Upon termination, you will pay for all work completed up to the termination date. I will provide all completed work and transfer any applicable rights as specified in the project agreement.

I reserve the right to terminate services immediately for non-payment, breach of terms, or unprofessional conduct.

Governing Law

These Terms and Conditions are governed by and construed in accordance with the laws of [Your State/Country]. Any disputes arising from these terms or services provided will be subject to the jurisdiction of the courts in [Your Location].

I encourage resolving any disputes through direct communication before pursuing legal action.

Contact Information

If you have questions about these Terms and Conditions or need clarification on any aspect of my services, please contact me:

• Email: [[email protected]]
• Phone: [your-phone-number]
• Address: [your-business-address]

These Terms and Conditions are effective as of September 22, 2025, and may be updated periodically. I will notify clients of any significant changes that may affect existing projects.